Whitson's house, the Crossways, stood from until the s. Soon afterward, attributed to the neighborhood's pride over their name,  p54 that sign was thrown into the Hudson River and replaced with the original Scarborough sign. The name originated in Ireland as that of the family home of John David Ogilby, a professor of ecclesiastical history at the General Theological Seminary.
Responsibilities of home improvement contractors. Action by the attorney general. As used in this article, the following terms, unless the context requires otherwise, shall have the following meanings: Such home improvement goods and services include burglar alarms, texture coating, fencing, air conditioning, heating equipment, and any english business writing new york ny goods which, at the time of sale or subsequently, are to be so affixed to real property by the home improvement contractor as to become a part of real property whether or not severable therefrom.
Home improvement contractor does not include a person, firm, corporation, landlord, cooperative corporation, condominium board of managers, joint tenant or co-tenant that owns, in whole or in part, the property to be improved.
Every home improvement contract subject to the provisions of this article, and all amendments thereto, shall be evidenced by a writing and shall be signed by all the parties to the contract. The writing shall contain the following: The name, address, telephone number and license number, if applicable, of the contractor.
The approximate dates, or estimated dates, when the work will begin and be substantially completed, including a statement of any contingencies that would materially change the approximate or estimated completion date.
In addition to the estimated or approximate dates, the contract shall also specify whether or not the contractor and the owner have determined a definite completion date to be of the essence. A description of the work to be performed, the materials to be provided to the owner, including make, model number or any other identifying information, and the agreed upon consideration for the work and materials.
A notice to the owner purchasing the home improvement that the contractor or subcontractor who performs on the contract or the materialman who provides home improvement goods or services and is not paid may have a claim against the owner which may be enforced against the property in accordance with the applicable lien laws.
Such home improvement contract shall also contain the following notice to the owner in clear and conspicuous bold face type: Any mechanic's lien filed against your property may be discharged. Payment of the agreed-upon price under the home improvement contract prior to filing of a mechanic's lien may invalidate such lien.
The owner may contact an attorney to determine his rights to discharge a mechanic's lien". A notice to the owner purchasing the home improvement that, except as otherwise provided in paragraph g of this subdivision, the home improvement contractor is legally required to deposit all payments received prior to completion in accordance with subdivision four of section seventy-one-a of the lien law and that, in lieu of such deposit, the home improvement contractor may post a bond, contract of indemnity or irrevocable letter of credit with the owner guaranteeing the return or proper application of such english business writing new york ny to the purposes of the contract.
If the contract provides for one or more progress payments to be paid to the home improvement contractor by the owner before substantial completion of the work, a schedule of such progress payments showing the amount of each payment, as a sum in dollars and cents, and specifically identifying the state of completion of the work or services to be performed, including any materials to be supplied before each such progress payment is due.
The amount of any such progress payments shall bear a reasonable relationship to the amount of work to be performed, materials to be purchased, or expenses for which the contractor would be obligated at the time of payment.
If the contract provides that the home improvement contractor will be paid on a specified hourly or time basis for work that has been performed or charges for materials that have been supplied prior to the time that payment is due, such payments for such work or materials shall not be deemed to be progress payments for the purposes of paragraph f of this subdivision, and shall not be required to be deposited in accordance with the provisions of paragraph e of this subdivision.
A notice to the owner that, in addition to any right otherwise to revoke an offer, the owner may cancel the home improvement contract until midnight of the third business day after the day on which the owner has signed an agreement or offer to purchase relating to such contract.
Cancellation occurs when written notice of cancellation is given to the home improvement contractor. Notice of cancellation, if given by mail, shall be deemed given when deposited in a mailbox properly addressed and postage prepaid. Notice of cancellation shall be sufficient if it indicates the intention of the owner not to be bound.
Notwithstanding the foregoing, this paragraph shall not apply to a transaction in which the owner has initiated the contact and the home improvement is needed to meet a bona fide emergency of the owner, and the owner furnishes the home improvement contractor with a separate dated and signed personal statement in the owner's handwriting describing the situation requiring immediate remedy and expressly acknowledging and waiving the right to cancel the home improvement contract within three business days.
For the purposes of this paragraph the term "owner" shall mean an owner or any representative of an owner. The writing shall be legible, in plain English, and shall be in such form to describe clearly any other document which is to be incorporated into the contract.
Before any work is done, the owner shall be furnished a copy of the written agreement, signed by the contractor. The writing may also contain other matters agreed to by the parties to the contract.
No home improvement contractor shall engage in any activity, transaction, or course of business or pay or receive any fee, payment, money, or other thing of value in connection with the financing of a home improvement contract without fully disclosing such activity, transaction, or course of business and any fees, payment, or other thing of value paid or to be paid in connection therewith, and without having obtained the agreement in writing from all parties to the transaction to such activity and the payment therefor.
Any owner who is induced to contract for a home improvement, in reliance on false or fraudulent written representations or false written statements, may sue and recover from such contractor a penalty of five hundred dollars plus reasonable attorney's fees, in addition to any damages sustained by the owner by reason of such statements or representations.
In addition, if the court finds that the suit by the owner was without arguable legal merit, it may award reasonable attorney's fees to the contractor.
Nothing in this article shall impair, limit, or reduce the statutory, common law or contractual duties or liability of any contractor.
Every home improvement contractor who violates any of the provisions of this article shall be subject to a civil penalty not to exceed one hundred dollars. Every home improvement contractor who fails to deposit funds in an escrow account or provide a bond or contract of indemnity or irrevocable letter of credit in compliance with the requirements of section seventy-one-a of the lien law, or who fails to provide a written contract substantially in compliance with the requirements of this article, shall be subject to a civil penalty not to exceed the greater of two hundred fifty dollars for each violation or five percent of the aggregate contract price specified in the home improvement contract; provided, however, that in no event shall the total penalty exceed twenty-five hundred dollars for each contract.
In an instance where the contractor has been shown to have committed multiple violations of this article or the provisions of section seventy-one-a of the lien law, the court shall consider the following factors in assessing a civil penalty pursuant to subdivision two of this section: No home improvement contractor shall be subject to the increased penalties provided by subdivision two of this section if such contractor shows by a preponderance of the evidence that the violation was not intentional and resulted from a bona fide error made notwithstanding the maintenance of procedures reasonably adopted to avoid such a violation.
Upon any violation of the provisions of this article, an application may be made by the attorney general in the name of the people of the state of New York to a court or justice having jurisdiction to issue an injunction, and upon notice to the defendant of not less than five days, to enjoin and restrain the continuance of the violation.Here is the definitive list of New York's business english lessons as rated by the New York, NY community.
Want to see who made the cut? Concordia College New York is a Christian higher education community of learning where mutual respect flourishes, responsibility is developed and reverence for God is cultivated so that students can pursue lives of passion, purpose and service.
Study English Language (ESL) in New York City (NYC) New York English Academy is located in the heart of lower Manhattan -- the Financial District. The Westies: Inside New York's Irish Mob - Kindle edition by T. J. English. Download it once and read it on your Kindle device, PC, phones or tablets.
Use features like bookmarks, note taking and highlighting while reading The Westies: Inside New York's Irish Mob. favorite this post Nov 20 NEED PROFESSIONAL SPANISH TRANSLATION ASAP (Greenwich Village) map hide this posting restore restore this posting.
favorite this post Nov 19 Writer for Product Evaluation pic map hide this posting restore restore this posting. favorite this post Nov 19 Social Media for Book launch / Author's assistant (NYC) map hide this posting restore restore this posting.
A collaboration of community, academic, and public health stakeholders using community partnerships, health training, program evaluation, information technology, and infrastructure to improve the health of the Harlem community.